You are here: / / ​ A SUBCONTRACTOR’S DAMAGES FOR CONSTRUCTION DELAY CANNOT BE PROVEN B...

​ A SUBCONTRACTOR’S DAMAGES FOR CONSTRUCTION DELAY CANNOT BE PROVEN BY COMPARING ACTUAL COSTS TO THE BID PRICE (FOURTH DEPT).

The Fourth Department, reversing (modifying) Supreme Court, determined the subcontractor (Frey) did not submit sufficient proof of damages caused by construction delays:

… [W]here a subcontractor is claiming delay damages, the subcontractor “must establish the extent to which its costs were increased by the improper acts because its recovery will be limited to damages actually sustained” … . “[I]t has repeatedly been held improper to prove excess labor costs by comparing the total labor costs for the project with the bid estimate for the labor, because of[, among other things,] the inherent unreliability of the price elements of a bid” … . LPCiminelli, Inc. v JPW Structural Contr., Inc., 2023 NY Slip Op 03112, Fourth Dept 6-9-23

Practice Point: A subcontractor’s damages for construction delay cannot be proven by comparing actual costs to the bid price.

 

You might also like
DEFENDANT DOG OWNER’S ACKNOWLEDGMENT SHE HAD HEARD THAT ONE OF HER DOGS NIPPED A BOY IN A PRIOR INCIDENT WAS NOT ADMISSIBLE EVIDENCE OF THE FACTS OF THE INCIDENT; THEREFORE PLAINTIFFS’ MOTION FOR SUMMARY JUDGMENT IN THIS DOG BITE CASE SHOULD NOT HAVE BEEN GRANTED (FOURTH DEPT).
ALTHOUGH THE PEOPLE SHOULD HAVE DISCOVERED THE PROBLEM WITH CERTAIN EVIDENCE SOONER, FOR SPEEDY TRIAL PURPOSES THE PEOPLE CAN BE CHARGED ONLY WITH THE TIME NECESSARY TO INVESTIGATE THE NEWLY DISCOVERED EVIDENTIARY ISSUE; THE NEED FOR MORE INVESTIGATION DID NOT INVALIDATE THE PEOPLE’S STATEMENT OF READINESS WHICH WAS WITHDRAWN; THEREFORE THE INDICTMENT SHOULD NOT HAVE BEEN DISMISSED ON SPEEDY TRIAL GROUNDS (FOURTH DEPT).
PLAINTIFFS RAISED A QUESTION OF FACT WHETHER THE CONTINUOUS REPRESENTATION DOCTRINE RENDERED THE LEGAL MALPRACTICE ACTION TIMELY; REFERENCE TO THE “ENFORCEMENT” OF THE LOAN DOCUMENTS INDICATED THE POSSIBILITY OF REPRESENTATION AFTER THE DATE OF THE LOAN TRANSACTION (FOURTH DEPT).
DEFENDANT TOLD THE POLICE HE DIDN’T WANT TO TALK, HIS STATEMENT SHOULD HAVE BEEN SUPPRESSED BUT THE ERROR WAS HARMLESS; CONSECUTIVE SENTENCES FOR POSSESSION OF THE KNIFE AND MURDER BY STABBING FOUND PROPER (FOURTH DEPT).
EVIDENCE DEFENDANT CONSTRUCTIVELY POSSESSED DRUGS THAT WERE LOCATED IN HIS SISTER’S (NOT HIS) RESIDENCE SUFFICIENT, SENTENCE REDUCED IN THE INTEREST OF JUSTICE (FOURTH DEPT).
PARK SAFETY IS A PROPRIETARY FUNCTION WHICH DOES NOT TRIGGER GOVERNMENTAL IMMUNITY, PLAINTIFF BITTEN BY A RABID FOX IN A STATE PARK, PLAINTIFF’S MOTION FOR SUMMARY JUDGMENT ON LIABILITY PROPERLY GRANTED (FOURTH DEPT).
THE PEOPLE DID NOT PROVE THE ALLEGED ACTS OF SEXUAL MISCONDUCT OCCURRED AT LEAST 24 HOURS APART; THEREFORE THE PEOPLE DID NOT PRESENT PROOF SUPPORTING A 20 POINT ASSESSMENT FOR A “CONTINUOUS COURSE OF SEXUAL MISCONDUCT:” LEVEL THREE REDUCED TO LEVEL TWO (FOURTH DEPT).
DEFENDANT WAS CONVICTED OF STABBING THE VICTIM AT A CROWDED PARTY BUT NO ONE SAW DEFENDANT WITH A KNIFE; DEFENSE REQUEST FOR THE CIRCUMSTANTIAL EVIDENCE JURY INSTRUCTION SHOULD HAVE BEEN GRANTED; CONVICTION REVERSED (FOURTH DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

AN ORAL STIPULATION IS INVALID PURSUANT TO DOMESTIC RELATIONS LAW SECION 236(B)(3)... IN A SIDEWALK SLIP AND FALL CASE AGAINST A MUNICIPALITY, VERBAL NOTICE OF THE...