You are here: / / FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN...
,

FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES.

The Second Department, reversing Supreme Court, determined plaintiff was not entitled to [construction] delay damages because plaintiff did not strictly comply with the delay-notice requirements spelled out in the contract as a condition precedent:

“Where a construction contract contains a condition precedent-type notice provision setting forth the consequences of a failure to strictly comply,' strict compliance will be required”… . Express conditions precedent “must be literally performed; substantial performance will not suffice,” and “[f]ailure to strictly comply with such provisions generally constitutes a waiver of a claim” … .

Here, article 11 of the primary contract between the defendant and the City, which is incorporated into the subcontract, contains such a condition-precedent type notice provision. Article 11.1.2 requires a contractor claiming to be sustaining delay damages to submit, “within forty-five (45) Days from the time such damages are first incurred, and every thirty (30) Days thereafter for as long as such damages are incurred, verified statements of the details and amounts of such damages, together with documentary evidence of such damages.” Moreover, pursuant to article 11.2, a failure “to strictly comply with the requirements of Article . . . 11.1.2 shall be deemed a conclusive waiver by the Contractor of any and all claims for damages for delay arising from such condition.”

The letters and emails relied upon by the Supreme Court and the plaintiff did not strictly comply with the contractual notice requirement, since they did not contain verified statements of the amount of delay damages allegedly sustained by the plaintiff and were unsupported by documentary evidence … . Schindler El. Corp. v Tully Constr. Co., Inc., 2016 NY Slip Op 03868, 2nd Dept 5-18-16

CONTRACT LAW (FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/LABOR-CONSTRUCTION LAW (FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/CONSTRUCTION CONTRACTS (DELAY DAMAGES, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/DELAY DAMAGES (CONSTRUCTION CONTRACTS, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/CONDITIONS PRECEDENT (CONSTRUCTION CONTRACTS, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)

You might also like
PLAINTIFF IN THIS FORECLOSURE ACTION DID NOT DEMONSTRATE “GOOD CAUSE” FOR AN EXTENSION OF TIME FOR SERVICE OF PROCESS, BUT DID DEMONSTRATE ENTITLEMENT TO AN EXTENSION IN THE “INTEREST OF JUSTICE” (SECOND DEPT).
THE PROPERTY OWNER, MCWHITE, HAD BEEN DISMISSED FROM THE ORIGINAL FORECLOSURE ACTION AND HER INTEREST IN THE PROPERTY HAD NOT BEEN EXTINGUISHED BY THE JUDGMENT OF FORECLOSURE WHICH FALSELY NAMED HER AS A DEFENDANT; THE REFEREE’S DEED-HOLDER DID NOT STATE A CAUSE OF ACTION FOR REFORECLOSURE AGAINST MCWHITE AND MCWHITE WAS ENTITLED TO SUMMARY JUDGMENT ON HER QUIET TITLE CAUSE OF ACTION (SECOND DEPT).
IN THIS NEGLIGENT SUPERVISION, HIRING AND RETENTION CASE, THE MEDICAL RECORDS OF A NON-PARTY WITNESS WHO ALLEGED IMPROPER CONDUCT BY DEFENDANT DOCTOR ARE DISCOVERABLE ONLY TO THE EXTENT THEY INCLUDE NON-PRIVILEGED INFORMATION INDICATING DEFENDANT DOCTOR’S EMPLOYER WAS AWARE OF THE ALLEGATIONS, THE NON-PARTY WITNESS DID NOT WAIVE THE PHYSICIAN-PATIENT PRIVILEGE BY DISCUSSING HER MEDICAL HISTORY IN A DEPOSITION (SECOND DEPT).
QUESTIONS OF FACT WHETHER THE DEFENDANT BUS DRIVER SAW WHAT SHOULD HAVE BEEN SEEN AND WHETHER THE EMERGENCY DOCTRINE APPLIED TO THIS REAR-END COLLISION CASE; THE BUS WAS BEHIND PLAINTIFF’S SCOOTER AND BOTH THE BUS AND THE SCOOTER APPARENTLY CHANGED LANES AT THE SAME TIME (SECOND DEPT).
PLAINTIFF HAD NO MEMORY OF EVENTS BEYOND WALKING TOWARD THE BUS AT A BUS STOP; SHE SUFFERED A CRUSHED FOOT; THE MOTION TO SET ASIDE THE PLAINTIFF’S VERDICT SHOULD HAVE BEEN GRANTED (SECOND DEPT).
PLAINTIFFS’ ATTORNEY PROPERLY WITHDREW ON IRRECONCILABLE DIFFERENCES GROUNDS AND WAS ENTITLED TO 95% OF THE CONTINGENCY FEE DESPITE THE FAILURE TO SUBMIT TIME RECORDS (SECOND DEPT).
THE FEDERAL OFFENSE WHICH SERVED AS A PREDICATE FOR DEFENDANT’S SECOND-FELONY-OFFENDER DESIGNATION DOES NOT REQUIRE THAT THE FIREARM INVOLVED BE OPERABLE; THE RELEVANT NEW YORK FELONY OFFENSE INCLUDES OPERABILITY AS AN ELEMENT; THEREFORE THE FEDERAL OFFENSE IS NOT A VALID PREDICATE OFFENSE (SECOND DEPT).
DEFENDANT WAS ENTITLED TO A HEARING ON HER MOTION TO DISMISS THE COMPLAINT FOR FAILURE OF PROPER SERVICE (SECOND DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

DOCTRINE OF DEFINITENESS WAS PROPERLY NOT APPLIED, DOLLAR-AMOUNT OF THE FEE... SIDEWALK WAS NOT USED AS A DANGEROUS INSTRUMENT IN THIS ASSAULT CASE.