You are here: / / Exceptions to “No-Damage-for-Delay” Clause in Construction Contract Exp...

Exceptions to “No-Damage-for-Delay” Clause in Construction Contract Explained

The defendant library was sued by the plaintiff contractor which claimed the library caused a delay in the performance of a contract by failing to secure access to an adjacent property which was necessary before plaintiff could complete the work.   In affirming the denial of summary judgment to the defendant library, the Second Department listed the exceptions to the enforceability of a “no-damage-for-delay” clause:

“A clause which exculpates a contractee from liability to a contractor for damages resulting from delays in the performance of the latter’s work is valid and enforceable and is not contrary to public policy if the clause and the contract of which it is a part satisfy the requirements for the validity of contracts generally”…. However, “even with such a clause, damages may be recovered for: (1) delays caused by the contractee’s bad faith or its willful, malicious, or grossly negligent conduct, (2) uncontemplated delays, (3) delays so unreasonable that they constitute an intentional abandonment of the contract by the contractee, and (4) delays resulting from the contractee’s breach of a fundamental obligation of the contract”….  Aurora Contrs Inc v West Babylon Pub Lib, 2013 NY Slip Op 04762, 2nd Dept 6-26-13

 

You might also like
PLAINTIFF FELL FROM A SCAFFOLD THAT DID NOT HAVE SAFETY RAILINGS, SUMMARY JUDGMENT ON THE LABOR LAW 240 (1) AND 241 (6) CAUSES OF ACTION PROPERLY GRANTED (SECOND DEPT),
IN THIS HYBRID ARTICLE 78-DECLARATORY JUDGMENT ACTION, THE PORTIONS OF THE PETITION WHICH SOUGHT A DECLARATION THAT AMENDMENTS TO THE ZONING CODE ARE ILLEGAL AND RELATED DAMAGES SHOULD NOT HAVE BEEN DISMISSED, SUA SPONTE, IN THE ABSENCE OF A SPECIFIC DEMAND FOR DISMISSAL (SECOND DEPT).
THE STIPULATION SETTING A DATE FOR THE CLOSING ON DEFENDANT’S PURCHASE OF THE PROPERTY DID NOT INFORM DEFENDANT HE WOULD BE CONSIDERED TO BE IN DEFAULT IF THE CLOSING DID NOT TAKE PLACE BY THAT DATE; THEREFORE THERE WAS NO “TIME OF THE ESSENCE” AGREEMENT AND PLAINTIFF WAS NOT ENTITLED TO THE DOWN PAYMENT (SECOND DEPT).
HERE THE ARGUMENT THAT NECESSARY PARTIES HAD NOT BEEN JOINED SHOULD NOT HAVE BEEN REJECTED; THE PROPER REMEDY IS TO SUMMON THE NECESSARY PARTIES, NOT DISMISSAL (SECOND DEPT).
“Assault and Battery” Exclusion from Coverage Applied Even Though Plaintiff Was Not the Intended Target of the Assault
DEFENSE VERDICT IN THIS SLIP AND FALL CASES SHOULD HAVE BEEN SET ASIDE, THE JURY FOUND DEFENDANT NEGLIGENT BUT FURTHER FOUND THE NEGLIGENCE WAS NOT THE PROXIMATE CAUSE OF THE FALL, HOWEVER, THE NEGLIGENCE AND PROXIMATE CAUSE WERE INEXTRICABLY INTERTWINED (SECOND DEPT).
BECAUSE PLAINTIFF RECOVERED FROM THE OTHER DRIVER AN AMOUNT EQUAL TO THE LIMIT OF PLAINTIFF’S SUPPLEMENTARY UNINSURED/UNDERINSURED MOTORISTS (SUM) COVERAGE, PLAINTIFF WAS NOT ENTITLED TO ANY FURTHER RECOVERY.
THE PROOF OF THE AMOUNT DUE PURSUANT TO THE MORTGAGE WAS NOT SUPPORTED BY THE RELEVANT BUSINESS RECORDS; THEREFORE THE REFEREE’S REPORT SHOULD NOT HAVE BEEN CONFIRMED (SECOND DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

Motion for Default Judgment Should Have Been Denied; Motion to Compel Acceptance... “Standing” to Bring Foreclosure Action Defined