You are here: / / FAILURE TO COMPLY WITH THE NOTICE OF DEFAULT REQUIREMENTS IN THE BUILDING-CONSTRUCTION...

FAILURE TO COMPLY WITH THE NOTICE OF DEFAULT REQUIREMENTS IN THE BUILDING-CONSTRUCTION BOND PRECLUDED RECOVERY UNDER THE BOND FOR CONSTRUCTION DELAYS (FIRST DEPT).

The First Department, in a full-fledged opinion by Justice Friedman, determined plaintiff’s failure to comply with the notice of default requirements in the building-construction bond precluded recovery under the bond for construction delays:

With regard to the “trigger” of the surety’s obligation, paragraph 3 of the A312 bond provides that “the Surety’s obligation under this Bond shall arise after” … the beneficiary of the bond (1) has notified the surety and the principal that it is considering declaring a default and offered to confer with the surety and the principal to discuss how to proceed, (2) has declared a default and formally terminated the principal’s right to complete the contract no earlier than 20 days after the aforementioned notice, and (3) has agreed to pay the balance of the contract price to the surety or to a new contractor chosen by the surety. * * *

​Upon [plaintiff’s] appeal, we affirm on the ground that JDS’s claim for delay damages under the 36-floor bond is barred by [plaintiff’s] failure to have complied, at any time before the bonded work had been completed, with the condition precedent of the notice and termination procedures specified in paragraph 3 of the bond. JDS Dev. LLC v Parkside Constr. Bldrs. Corp., 2024 NY Slip Op 04227, First Dept 8-15-24

Practice Point: Compliance with the notice of default provisions in an A312 building-construction bond is a condition precedent to recovery under the bond for construction delays.​

 

You might also like
THREE YEAR STATUTE OF LIMITATIONS FOR A FALSE ARREST CAUSE OF ACTION UNDER 42 USC 1983 BEGAN TO RUN UPON ARRAIGNMENT.
Loud Argument With Another Teacher In Front of Students Did Not Justify an Unsatisfactory Rating and Discharge of Probationary Teacher
Error to Charge Jury on Comparative Negligence/Inadequate Awards for Pain and Suffering and Loss of Consortium
THE SEARCH WAS NOT INCIDENT TO ARREST AS THE SUPPRESSION COURT RULED, CASE REMITTED FOR CONSIDERATION OF AN ALTERNATE GROUND FOR A VALID SEARCH WHICH WAS ARGUED BUT NOT RULED UPON BELOW. ​
EVIDENCE BUILDING OWNER HAD KNOWLEDGE OF THE ELEVATOR MISLEVELING, EVIDENCE THE ELEVATOR MAY NOT HAVE BEEN PROPERLY MAINTAINED, AND THE APPLICABILITY OF RES IPSA LOQUITUR REQUIRED DENIAL OF DEFENDANTS’ MOTIONS FOR SUMMARY JUDGMENT IN THIS SLIP AND FALL CASE (FIRST DEPT).
BY CONCEDING DEFENDANT SUFFERED FROM A DANGEROUS MENTAL CONDITION DEFENSE COUNSEL EFFECTIVELY WAIVED AN INITIAL ‘TRACK’ HEARING PURSUANT TO CPL 330.20, A ‘CRITICAL STAGE’ OF THE PROCEEDINGS AFTER A NOT RESPONSIBLE BY REASON OF MENTAL DISEASE OR DEFECT PLEA, DEFENSE COUNSEL WAS INEFFECTIVE, CPL 330.20 HEARING ORDERED (FIRST DEPT).
THERE IS NO HEIGHTENED PLEADING REQUIREMENT FOR CONSEQUENTIAL DAMAGES STEMMING FROM A BREACH OF AN INSURANCE CONTRACT, PLAINTIFF ALLEGED THE INSURER’S DELAY IN PAYING THE CLAIM FOR DAMAGE TO PLAINTIFF’S BUILDING, WHICH SHIFTED WHEN WORK WAS DONE ON AN ADJOINING BUILDING, RESULTED IN AN ARRAY OF CONSEQUENTIAL DAMAGES, THE CONSEQUENTIAL DAMAGES ASPECT OF THE COMPLAINT SHOULD NOT HAVE BEEN DISMISSED (FIRST DEPT).
WHERE THE CRITERIA ARE MET SENTENCING AS A PREDICATE FELON IS MANDATORY, DEFENDANT SHOULD HAVE BEEN SO SENTENCED BUT WAS NOT, PEOPLE’S MOTION TO SET ASIDE THE ILLEGAL SENTENCE PROPERLY BROUGHT AND GRANTED.

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

HERE THE MARINA OWNER SERVED THE BOAT OWNER WITH A NOTICE OF SALE (FOR FAILURE... HERE THE COMPLAINT STATED A CHILD-VICTIMS-ACT CAUSE OF ACTION AGAINST THE STATE;...