You are here: / / Contract Provision Protected Contractee from Damages for Delay Caused by...

Contract Provision Protected Contractee from Damages for Delay Caused by Regulators​

In a full-fledged opinion by Justice Mazzarelli, the First Department determined, among many other contract-issues, that delays allegedly caused by regulators (re: asbestos-removal) were included in the contract provision which insulated the contractee from delay-related damages:

“A clause which exculpates a contractee from liability to a contractor [Bovis] for damages resulting from delays in the performance of the latter’s work is valid and enforceable and is not contrary to public policy if the clause and the contract of which it is a part satisfy the requirements for the validity of contracts generally”…. However, such a clause may be disregarded under certain recognized exceptions, including one for delays that are “uncontemplated” …. Delays are not considered uncontemplated when they “are reasonably foreseeable, arise from the contractor’s work during performance, or . . . are mentioned in the contract” …. Further, a party seeking to invoke any of the exceptions to the general rule that no damages for delay clauses are enforceable bears a heavy burden … .

Here, Bovis failed to carry its heavy burden. The contract specifically anticipated the possibility that the involvement of regulators would delay the process. Again, Bovis expressly acknowledged that it assumed the “risk of all regulatory and other Governmental Authority delays.” Certainly this lifted the no damages for delay clause out of the exception for uncontemplated delays. There is no basis for Bovis to argue that by alleging that the extent of the regulatory delays was extreme and unprecedented it stated a claim for delay damages. As this Court has stated in finding a no damages for delay clause enforceable, “[W]hile the conditions themselves may not have been anticipated, the possibility, however unlikely, of their arising was contemplated and addressed by the parties in their agreement” … .  Bovis Lend Lease (LMB), Inc v Lower Manhattan Dev Corp, 2013 NY Slip Op 03804, 1st Dept, 5-28-13

CONSTRUCTION CONTRACT

You might also like
State Equal Access to Justice Act 
ALTHOUGH THE FREE-STANDING BRACE FRAME WAS AT THE SAME LEVEL AS PLAINTIFF AT THE TIME IT FELL OVER, PLAINTIFF WAS ENTITLED TO SUMMARY JUDGMENT ON HIS LABOR LAW 240 (1) CAUSE OF ACTION (FIRST DEPT).
WHERE THE EMPLOYER OF A PHYSICIAN HAS PAID THE PREMIUMS FOR MEDICAL MALPRACTICE INSURANCE AND THE INSURANCE COMPANY DEMUTUALIZES, ABSENT AN AGREEMENT TO THE CONTRARY, THE PROCEEDS GO TO THE PHYSICIAN, NOT THE EMPLOYER (FIRST DEPT). ​
THERE IS A QUESTION OF FACT WHETHER DEFENDANTS HAD CONSTRUCTIVE NOTICE OF THE WORN STEP IN THIS SLIP AND FALL CASE; DEFENDANTS’ MOTION FOR SUMMARY JUDGMENT SHOULD NOT HAVE BEEN GRANTED (FIRST DEPT).
PLAINTIFFS FELL FROM A LIFT TRUCK WHICH WAS STRUCK BY A BUS, SUMMARY JUDGMENT ON THE LABOR LAW 240 (1) CAUSE OF ACTION SHOULD HAVE BEEN GRANTED; HEARSAY ALONE WILL NOT DEFEAT A MOTION FOR SUMMARY JUDGMENT (FIRST DEPT).
QUESTION OF FACT WHETHER THE RECKLESS STANDARD APPLIED IN THIS PEDESTRIAN-POLICE CAR ACCIDENT CASE (FIRST DEPT).
PURPORTED ORAL AGREEMENT TO PURCHASE ART WORKS BY PLAINTIFF PETER BEARD BARRED BY THE STATUTE OF FRAUDS, PAYMENTS ALLEGEDLY MADE TO PLAINTIFF WERE NOT UNEQUIVOCALLY REFERABLE TO THE ALLEGED CONTRACT (FIRST DEPT).
INABILITY TO IMPOSE THE PROMISED SENTENCE REQUIRED THAT DEFENDANT’S GUILTY PLEA BE VACATED (FIRST DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2025 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

Retainer Agreement in Divorce Action Which Addressed Only Work “Up To” Trial... Grabbing and Spinning a Person Does Not Constitute Unlawful Imprisonment​