You are here: / / FAILURE TO COMPLY WITH THE NOTICE OF DEFAULT REQUIREMENTS IN THE BUILDING-CONSTRUCTION...

FAILURE TO COMPLY WITH THE NOTICE OF DEFAULT REQUIREMENTS IN THE BUILDING-CONSTRUCTION BOND PRECLUDED RECOVERY UNDER THE BOND FOR CONSTRUCTION DELAYS (FIRST DEPT).

The First Department, in a full-fledged opinion by Justice Friedman, determined plaintiff’s failure to comply with the notice of default requirements in the building-construction bond precluded recovery under the bond for construction delays:

With regard to the “trigger” of the surety’s obligation, paragraph 3 of the A312 bond provides that “the Surety’s obligation under this Bond shall arise after” … the beneficiary of the bond (1) has notified the surety and the principal that it is considering declaring a default and offered to confer with the surety and the principal to discuss how to proceed, (2) has declared a default and formally terminated the principal’s right to complete the contract no earlier than 20 days after the aforementioned notice, and (3) has agreed to pay the balance of the contract price to the surety or to a new contractor chosen by the surety. * * *

​Upon [plaintiff’s] appeal, we affirm on the ground that JDS’s claim for delay damages under the 36-floor bond is barred by [plaintiff’s] failure to have complied, at any time before the bonded work had been completed, with the condition precedent of the notice and termination procedures specified in paragraph 3 of the bond. JDS Dev. LLC v Parkside Constr. Bldrs. Corp., 2024 NY Slip Op 04227, First Dept 8-15-24

Practice Point: Compliance with the notice of default provisions in an A312 building-construction bond is a condition precedent to recovery under the bond for construction delays.​

 

You might also like
THE JUDGE DID NOT MAKE EVEN A “MINIMAL INQUIRY” WHEN DEFENDANT STATED HE WANTED ANOTHER ATTORNEY; DEFENDANT DID NOT ABANDON THE ISSUE BY NOT RAISING IT AGAIN WHEN HE PLED GUILTY; PLEA VACATED (FIRST DEPT).
SIX YEAR STATUTE OF LIMITATIONS APPLIES TO FRAUD ACTIONS AGAINST DEFENDANT BANK RELATING TO THE SALE OF RESIDENTIAL MORTGAGE-BACKED SECURITIES BROUGHT PURSUANT TO THE MARTIN ACT AND EXECUTIVE LAW 63.
BUILDING INSPECTION REPORT STATED STAIRWAY WHERE PLAINTIFF FELL WAS IN NEED OF REPAIR, DEFENDANT SUBMITTED EVIDENCE OF GENERAL CLEANING PRACTICES, THEREFORE DEFENDANT DID NOT DEMONSTRATE IT DID NOT HAVE CONSTRUCTIVE OR ACTUAL NOTICE OF THE ALLEGED CRACK IN THE STAIRWAY (FIRST DEPT).
HEATING AGREEMENT WAS A COVENANT WHICH RUNS WITH THE LAND, ORAL WAIVER MAY BE VALID DESPITE WRITING REQUIREMENT IN THE COVENANT.
DEFENSE COUNSEL TOLD THE COURT DURING THE PRE-TRIAL SUPPRESSION HEARING THAT DEFENDANT WAS NOT CONTESTING HIS CONSENT TO THE INTOXILYZER BREATH TEST; SUPREME COURT PROPERLY DENIED DEFENDANT’S ATTEMPT TO RAISE THAT SAME SUPPRESSION ISSUE DURING TRIAL; THE DISSENT DISAGREED (FIRST DEPT).
PLAINTIFF DID NOT SUFFICIENTLY ALLEGE THAT NEW YORK’S PROPERTY TAX SYSTEM DISCRIMINATES AGAINST PROPERTY OWNERS IN “MAJORITY-MINORITY” NEIGHBORHOODS; COMPLAINT SHOULD HAVE BEEN DISMISSED IN ITS ENTIRETY (FIRST DEPT).
DEFENDANT PROPERTY OWNER/MANAGER’S MOTION FOR SUMMARY JUDGMENT SHOULD HAVE BEEN GRANTED; DEFENDANTS DEMONSTRATED THEY DID NOT HAVE NOTICE OF ANY PROBLEMS WITH A DOOR WHICH ALLEGEDLY MALFUNCTIONED CAUSING PLAINTIFF’S DECEDENT TO FALL OUT OF A WHEELCHAIR LIFT (FIRST DEPT).
NO CAUSE OF ACTION FOR BREACH OF FIDUCIARY DUTY AGAINST INDIVIDUAL COOPERATIVE BOARD MEMBERS, MEMBERS OF THE BOARD DID NOT PARTICIPATE IN A CORPORATE TORT (FIRST DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

HERE THE MARINA OWNER SERVED THE BOAT OWNER WITH A NOTICE OF SALE (FOR FAILURE... HERE THE COMPLAINT STATED A CHILD-VICTIMS-ACT CAUSE OF ACTION AGAINST THE STATE;...