You are here: / / ​ A SUBCONTRACTOR’S DAMAGES FOR CONSTRUCTION DELAY CANNOT BE PROVEN B...

​ A SUBCONTRACTOR’S DAMAGES FOR CONSTRUCTION DELAY CANNOT BE PROVEN BY COMPARING ACTUAL COSTS TO THE BID PRICE (FOURTH DEPT).

The Fourth Department, reversing (modifying) Supreme Court, determined the subcontractor (Frey) did not submit sufficient proof of damages caused by construction delays:

… [W]here a subcontractor is claiming delay damages, the subcontractor “must establish the extent to which its costs were increased by the improper acts because its recovery will be limited to damages actually sustained” … . “[I]t has repeatedly been held improper to prove excess labor costs by comparing the total labor costs for the project with the bid estimate for the labor, because of[, among other things,] the inherent unreliability of the price elements of a bid” … . LPCiminelli, Inc. v JPW Structural Contr., Inc., 2023 NY Slip Op 03112, Fourth Dept 6-9-23

Practice Point: A subcontractor’s damages for construction delay cannot be proven by comparing actual costs to the bid price.

 

You might also like
THE ADMINISTRATIVE RECORD SUPPORTED THE GRANT OF THE ARIA VARIANCE BY THE ZONING BOARD OF APPEALS; SUPREME COURT SHOULD NOT HAVE SUBSTITUTED ITS JUDGMENT FOR THE BOARD’S (FOURTH DEPT).
DEFENDANTS’ MOTION FOR SUMMARY JUDGMENT IN THIS FARM EQUIPMENT PRODUCTS LIABILITY ACTION SHOULD HAVE BEEN GRANTED (FOURTH DEPT).
PLAINTIFF RAISED A QUESTION OF FACT WHETHER PLAINTIFF’S DECEDENT’S FALL FROM HER BED IN A NURSING HOME WAS CAUSED BY DEFENDANTS’ NEGLIGENCE (FOURTH DEPT).
DEFENDANT GENERAL CONTRACTOR DID NOT EXERCISE SUPERVISORY CONTROL OVER THE PLAINTIFF OR PLAINTIFF’S CO-WORKER WHO INJURED PLAINTIFF, THE FACT THAT DEFENDANT GENERAL CONTRACTOR SUPPLIED THE EQUIPMENT WHICH INJURED PLAINTIFF DID NOT GIVE RISE TO LIABILITY ON THE GENERAL CONTRACTOR’S PART (FOURTH DEPT).
BAD FAITH DISCLAIMER ACTION BROUGHT AFTER INJURED PLAINTIFFS WERE ASSIGNED THE INSURED’S RIGHTS UNDER THE POLICY NOT BARRED BY RES JUDICATA, PLAINTIFFS DID NOT HAVE STANDING TO BRING THE BAD FAITH ACTION UNTIL THE RIGHTS WERE ASSIGNED (FOURTH DEPT). ​
FAMILY COURT JUDGE SHOULD HAVE RECUSED HERSELF AFTER DEATH THREAT BY FATHER.
ALTHOUGH THE EVIDENCE OF DEFENDANT’S CONSTRUCTIVE POSSESSION OF DRUGS AND DRUG PARAPHERNALIA FOUND IN HIS GIRLFRIEND’S APARTMENT WAS DEEMED LEGALLY SUFFICIENT, THE FINDING THAT DEFENDANT CONSTRUCTIVELY POSSESSED THE DRUGS AND PRAPHERNALIA WAS DEEMED AGAINST THE WEIGHT OF THE EVIDENCE (FOURTH DEPT).
DEFENDANT’S AGREEMENT TO PURCHASE PLAINTIFF’S BUSINESS WAS NOT ENTWINED WITH AN EMPLOYMENT AGREEMENT BETWEEN PLAINTIFF AND DEFENDANT WHICH INCLUDED A COVENANT NOT TO COMPETE; THEREFORE PLAINTIFF’S ALLEGED BREACH OF THE COVENANT NOT TO COMPETE WAS NOT A DEFENSE TO DEFENDANT’S BREACH OF THE PURCHASE AND SALE AGREEMENT (FOURTH DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

AN ORAL STIPULATION IS INVALID PURSUANT TO DOMESTIC RELATIONS LAW SECION 236(B)(3)... IN A SIDEWALK SLIP AND FALL CASE AGAINST A MUNICIPALITY, VERBAL NOTICE OF THE...