You are here: / / IN A CONSTRUCTION CONTRACT TRIAL, IT IS IMPROPER TO DETERMINE ADDITIONAL...
,

IN A CONSTRUCTION CONTRACT TRIAL, IT IS IMPROPER TO DETERMINE ADDITIONAL LABOR COST DUE TO DELAY BY USING A DEFENDANT’S PRECONTRACT ESTIMATE OF LABOR COST (FIRST DEPT).

The First Department, reversing (modifying) Supreme Court in this construction contract case, determined the labor cost associated with a delay could not be determined by using the defendant’s precontract estimate of what its labor cost would be:

The trial court should not have awarded damages for additional labor costs due to defendants’ delays in the construction project. In general, it is impermissible to calculate delay damages for additional labor costs based on a comparison of the contractor’s precontract estimate of what its labor cost would be and what it claimed its labor cost actually turned out to be … . Nevertheless, in calculating the additional labor costs that plaintiff incurred from defendants’ delays, plaintiff’s expert improperly used plaintiff’s pre-bid estimate of the project’s expected labor costs, and Supreme Court erred in basing the award on this improper method of calculation. Five Star Elec. Corp. v A.J. Pegno Constr. Co., Inc./Tully Constr. Co., Inc.,2022 NY Slip Op 05659, First Dept 10-11-22

Practice Point: Here in this construction-contract trial, plaintiff’s expert should not have calculated the additional labor cost due to delay by using the defendant’s precontract labor cost estimate.

 

You might also like
THE PROOF AT TRIAL DID NOT DEMONSTRATE PLAINTIFF INHALED SUFFICIENT LEVELS OF ASBESTOS WHEN USING DEFENDANT’S TALCUM POWDER TO HAVE CAUSED HER MESOTHELIOMA; DEFENDANT’S MOTION TO SET ASIDE THE VERDICT AS A MATTER OF LAW SHOULD HAVE BEEN GRANTED (FIRST DEPT). ​
DEFENDANTS’ ATTORNEYS HAD APPARENT AUTHORITY TO BIND DEFENDANTS TO THE OPEN-COURT STIPULATED SETTLEMENT OF $8,875,000; IN ADDITION, DEFENDANTS RATIFIED THE STIPULATION BY FAILING TO TIMELY OBJECT TO IT (FIRST DEPT).
THE APPEAL WAIVER WAS INVALID, CRITERIA EXPLAINED; THERE ARE UNRESOLVED QUESTIONS (RAISED BY A DEFENSE INVESTIGATION SUBMITTED WITH THE MOTION TO SUPPRESS) ABOUT WHETHER THE DESCRIPTON OF THE SEARCHED PREMISES IN THE WARRANT WAS ACCURATE, REQUIRING A HEARING; MATTER REMANDED (FIRST DEPT
DEFENSE MOTION TO SET ASIDE THE VERDICT BASED UPON THE ALLEGED MISCONDUCT OF TWO JURORS SHOULD NOT HAVE BEEN DENIED WITHOUT A HEARING (FIRST DEPT).
CONTRACT NOT ACTIONABLE BECAUSE IT DID NOT SPELL OUT THE CONSIDERATION FOR A PAST OR EXECUTED PROMISE, DECISION ON A MOTION TO DISMISS DOES NOT BECOME THE LAW OF THE CASE IN A SUBSEQUENT MOTION FOR SUMMARY JUDGMENT (FIRST DEPT).
THE FACT THAT THE CITY BUILDING CODE DID NOT REQUIRE DISABLED-ACCESS TO THE THIRD FLOOR OF DEFENDANT RESTAURANT DID NOT CONFLICT WITH THE FACT THAT THE HUMAN RIGHTS LAW MAY REQUIRE SUCH ACCESS (FIRST DEPT).
Janitorial Schedule Alone Not Enough to Demonstrate Lack of Constructive Notice
THE INSURED, SPACE NEEDLE, LLC, IS LOCATED IN WASHINGTON STATE; ALTHOUGH THE INSURANCE POLICY NAMED NEW YORK AS THE FORUM AND REQUIRED THE APPLICATION OF NEW YORK LAW FOR ANY LAWSUITS, THE WASHINGTON INSURANCE CODE RENDERED SUCH PROVISIONS VOID; THEREFORE THE INSURER WAS NOT ENTITLED TO AN ANTI-SUIT PRELIMINARY INJUNCTION IN NEW YORK (FIRST DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

THE PHRASE “CONSUMMATION OF THE ANTICIPATED MARRIAGE” IN THE PRENUPTIAL... PLAINTIFF BICYCLIST STRUCK THE DOOR OF DEFENDANT’S VAN AFTER DEFENDANT...