You are here: / / DEFENDANT BREACHED THE CONTRACT BY FAILING TO COMPLY WITH THE NOTICE-TO-CURE...

DEFENDANT BREACHED THE CONTRACT BY FAILING TO COMPLY WITH THE NOTICE-TO-CURE PROVISION BEFORE TERMINATING IT; THE REASON FOR TERMINATION, FAULTY WORK, WAS NOT EXEMPT FROM THE NOTICE-TO-CURE REQUIREMENT (FIRST DEPT).

The First Department, in a full-fledged opinion by Justice Acosta, determined defendant breached the contract by failing to comply with the notice-to-cure provision before terminating it. Defendant general contractor (Borough) subcontracted with plaintiff to perform steel work at a residential development project. The subcontract required plaintiff to supply and install steel for excavation support and the frame of the building, as well as provide a full-time safety manager and procure permits for a crane:

… [P]laintiff alleges that defendant failed to comply with the notice-to-cure provision before terminating the contract, gives us the opportunity to address the strict nature of these types of provisions and the very rare instances when they can be ignored. Defendant general contractor terminated the steel work subcontract it had entered into with plaintiff based on what was essentially a claim that plaintiff provided faulty work. … [D]efendant was obligated to give plaintiff the 10-day notice to cure provided in the contract … [.] [F]aulty work does not fall within the very limited and rare circumstances when the provision can be dispensed with, namely, where the other party expressly repudiates the contract or abandons performance or where the breach is impossible to cure. * * *

Borough sent plaintiff a written “notice of termination” stating that the subcontract would be terminated in three days from the date of the letter and that plaintiff was in default by “failing to provide sufficient manpower [] [and] failing to meet the schedule, safety regulations and qualified workmanship for the Project.” The letter further stated that plaintiff “failed to respond or delayed response to requests for crane usage” and “has delayed the performance and completion of the work.” * * *

Nothing in the record supports the conclusion that the plaintiff repudiated or abandoned the contract or could not have commenced and continued correction of the steel frame and other alleged safety violations in the 10-day period following receipt of notice to cure. … [T]he alleged default, faulty steelwork, constitutes nothing more than defective performance, which is “the very situation to which the cure provision was intended to apply” … . East Empire Constr. Inc. v Borough Constr. Group LLC, 2021 NY Slip Op 05455, First Dept 10-12-2​1

 

You might also like
SUMMARY JUDGMENT SHOULD NOT HAVE BEEN GRANTED TO THE CLUB AND THE SECURITY COMPANY IN THIS THIRD PARTY ASSAULT CASE; THERE WERE QUESTIONS OF FACT ABOUT WHETHER THE CLUB COULD BE HELD RESPONSIBLE FOR CRIMINAL ACTIVITY IN THE STREET IN FRONT OF THE CLUB, WHETHER THE CLUB WAS THE SPECIAL EMPLOYER OF THE BOUNCERS AND THEREFORE SUBJECT TO VICARIOUS LIABILITY, AND WHETHER THERE WAS DRAM SHOP ACT LIABILITY (FIRST DEPT). ​
PLAINTIFF, A SOPHISTICATED INVESTOR, DID NOT STATE A CAUSE OF ACTION FOR FRAUD ON THE PART OF THE COMPANY IN WHICH PLAINTIFF INVESTED AND PURCHASED A CONTROLLING INTEREST, PLAINTIFF HAD THE MEANS TO DISCOVER THE TRUTH BEHIND ANY ALLEGED FALSE CLAIMS.
DEFENDANT’S 2013 GUILTY PLEA WAS DEEMED DEFECTIVE BECAUSE THE JUDGE FAILED TO ENSURE THE DEFENDANT UNDERSTOOD THE CHARGE; BECAUSE THE 2013 CONVICTION WAS UNCONSTITUTIONALLY OBTAINED, IT CANNOT BE A BASIS, IN 2020, FOR SENTENCING THE DEFENDANT AS A PERSISTENT VIOLENT PREDICATE FELON; SENTENCE VACATED (FIRST DEPT).
Assumption of Risk Extends to Condition of Outside Basketball Court
Spoliation of Evidence.
DESPITE THE BRAKE-FAILURE ALLEGATION IN THIS REAR-END COLLISION CASE, PLAINTIFF’S MOTION FOR SUMMARY JUDGMENT SHOULD HAVE BEEN GRANTED; DEFENDANT DID NOT PRESENT SUFFICIENT EVIDENCE TO RAISE A QUESTION OF FACT ABOUT BRAKE FAILURE (FIRST DEPT).
Appellate Court Can Exercise Its Own Discretion Re: Scope of Discovery, Even in the Absence of Abuse
THERE WAS NO EVIDENCE THE POLICE ANNOUNCED THEIR PURPOSE (ARREST WARRANT) BEFORE ENTERING THE APARTMENT; THE MOTION TO SUPPRESS SHOULD HAVE BEEN GRANTED (FIRST DEPT). ​

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

DEFENDANT’S WAIVER OF APPEAL WAS UNENFORCEABLE; “DIFFICULTIES”... THIS PRODUCTS LIABILITY (DEFECTIVE DESIGN) ACTION AROSE FROM THE ROLLOVER OF...