You are here: / / “No Damages for Delay” and “Mandatory Notice” Clauses...

“No Damages for Delay” and “Mandatory Notice” Clauses Precluded Suit

The Third Department affirmed the dismissal of plaintiff’s breach of contract complaint, finding that the exceptions to the enforceability of a “no damages for delay” clause did not apply, and the “mandatory notice” clause precluded suit for “extra work.” Plaintiff was engaged by defendant to install heating, ventilation and air conditioning equipment:

As a general rule, “contract clauses exculpating the contractee from liability to the contractor for damages resulting from delays in performance of the contract work” are valid and enforceable … . However, even where the contract contains such a clause, there are several recognized exceptions. As relevant here, a contractor may still recover for “delays caused by the contractee’s bad faith or its willful, malicious, or grossly negligent conduct” … . A defendant seeking summary judgment dismissing a claim for delay damages “bears the initial burden of demonstrating prima facie that none of the exceptions to the ‘damages for delay’ clause are present” … .  * * *

… [P]laintiff attempts to claim compensation for tasks that allegedly constituted “extra work” beyond the scope of the parties’ contract. However, a provision in the contract required plaintiff to notify defendant that it considered a task to constitute extra work within 15 working days after being ordered to undertake the task or beginning to perform it. Here, plaintiff concedes that it did not notify defendant of this claim until five months after it began performance of the disputed task. Thus, “[d]efendant established its entitlement to summary judgment by submitting proof that [plaintiff] did not comply with the condition precedent” by providing timely notice … . Tougher Indus., Inc. v Dormitory Auth. of the State of N.Y., 2015 NY Slip Op 06388, 3rd Dept 7-30-15

 

You might also like
EVEN THOUGH DEFENDANT WAIVED HIS RIGHT TO BE PRESENT AT THE SORA RISK-LEVEL ASSESSMENT PROCEEDING, HE DID NOT WAIVE HIS RIGHT TO EFFECTIVE COUNSEL; COUNSEL DID NOT COMMUNICATE WITH DEFENDANT AND DID NOT PRESENT A DEFENSE; ORDER REVERSED (THIRD DEPT).
ELECTRIC GENERATING FACILITY WHICH USES HUDSON RIVER WATER TO COOL MACHINERY AND RETURNS WARM WATER TO THE RIVER WAS PROPERLY ALLOWED TO CONTINUE OPERATION UNDER RENEWED PERMITS 3RD DEPT.
ALTHOUGH THE EVIDENCE DEFENDANT ACTED AS AN ACCOMPLICE IN THE FATAL SHOOTING OF THE VICTIM WAS LEGALLY SUFFICIENT, THE CONVICTION WAS AGAINST THE WEIGHT OF THE EVIDENCE BECAUSE OF WEAKNESS OF THE EVIDENCE DEFENDANT KNEW OF THE SHOOTER’S INTENT TO KILL THE VICTIM, AS OPPOSED TO AN INTENT TO ROB OR ASSAULT (THIRD DEPT).
DEFENDANT ARGUED THE INSURANCE COMPANY WHICH REPRESENTED THE PROPERTY OWNER AND THE GENERAL CONTRACTOR IN THIS CONSTRUCTION ACCIDENT CASE UNFAIRLY APPORTIONED THE PAYMENT OF THE SETTLEMENT BETWEEN THEM SUCH THAT THE NON-NEGLIGENT, VICARIOUSLY LIABLE PARTY PAID $2 MILLION, AND THE NEGLIGENT PARTY PAID $200,000; AFTER INDEMNIFYING THE PROPERTY OWNER IN THE AMOUNT OF $2 MILLION DEFENDANT SOUGHT TO BE INDEMNIFIED BY THE NEGLIGENT PARTY; THE ATTEMPT WAS REJECTED UNDER BOTH CONTRACTUAL AND COMMON LAW INDEMNIFICATION THEORIES (THIRD DEPT).
Seasonal Residents Properly Deemed “Residents” of a Town for Election Purposes
Where There Has Been a Failure of a Material Condition of a Judicial Instrument of Surrender (of Guardianship and Custody of a Child), the Parent May Bring an Action to Revoke the Surrender Instrument
A REVOLVER WHICH COULD NOT BE CONNECTED TO THE SHOOTING SHOULD NOT HAVE BEEN ADMITTED IN EVIDENCE; ERROR HARMLESS HOWEVER (THIRD DEPT).
ANNOUNCING A NEW RULE GOVERNING THE DISCLOSURE OF PROSPECTIVE EXPERT WITNESS’S QUALIFICATIONS IN MEDICAL MALPRACTICE ACTIONS, THE THIRD DEPT REQUIRES COMPLETE DISCLOSURE OF THE QUALIFICATIONS, EVEN IF SUCH DISCLOSURE FACILITATES THE IDENTIFICATION OF THE WITNESS (THIRD DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

correspondence which was intended to lead to a settlement agreement (re: real... Failure to Directly Address a Juror’s Stated Bias Required Reversal—“Bright...