Material Breach and Abandonment of Subcontract Waived Notice of Termination and Opportunity to Cure and Warranted Cost-to-Complete Damages

The First Department explained the criteria for cost-to-complete damages for a subcontractor’s breach before completion of performance.  The court noted that plaintiff was not entitled to overpayment damages in addition to the cost-to-complete damages because receipt of both would amount to a double recovery:

Defendants are entitled to cost-to-complete damages because plaintiff materially breached and abandoned the subcontract, and waived any right to notice of termination or an opportunity to cure. The subcontract explicitly provides that time is of the essence, that plaintiff’s delay or failure to meet scheduling requirements warrants termination, and that plaintiff must perform work even if the parties dispute that work’s characterization, yet plaintiff repeatedly failed to timely perform and complete work, despite defendant E-J Electric Installation Co.’s repeated demands … . Among other material breaches, plaintiff repudiated the subcontract by abandoning the work site when only 73.49% of plaintiff’s work was complete … . Accordingly, plaintiff waived any right to notice of termination … .

It is well-settled that if a subcontractor breaches before completing performance, the contractor is entitled to recover reliance, or cost-to-complete damages from the subcontractor… . Kleinberg Elec Inc v E-J Elec Installation Co, 2013 NY Slip Op 07256, 1st Dept 11-7-13