You are here: / INSURER NOT OBLIGATED TO SATISFY JUDGMENT AGAINST ITS INSURED; INJURED...

Search Results

/

INSURER NOT OBLIGATED TO SATISFY JUDGMENT AGAINST ITS INSURED; INJURED PARTY FAILED TO TIMELY NOTIFY INSURER OF THE FIRE WHICH CAUSED THE DAMAGE.

The Second Department, reversing Supreme Court, determined plaintiff insurer was not required to satisfy the injured party's (Seville's) judgment against its insured because Seville did not timely notify plaintiff insurer of the fire which damaged Seville's property:

“Insurance Law § 3420(a)(2) expressly permits an injured party to recover any unsatisfied judgment against an insured, directly from the insurer” … . Insurance Law § 3420(a)(3) requires the injured party to demonstrate that he or she acted diligently in attempting to ascertain the identity of the insurer, and thereafter expeditiously notified the insurer … . “In determining the reasonableness of an injured party's notice, the notice required is measured less rigidly than that required of the insured[ ]” … . “The injured person's rights must be judged by the prospects for giving notice that were afforded him, not by those available to the insured” … . “What is reasonably possible for the insured may not be reasonably possible for the person he has injured. The passage of time does not of itself make delay unreasonable” … .

Here, the plaintiff made a prima facie showing that Seville failed to act diligently in attempting to ascertain the plaintiff's identity and in expeditiously notifying it. In opposition, Seville failed to raise a triable issue of fact … . Mt. Hawley Ins. Co. v Seville Electronics Trading Corp., 2016 NY Slip Op 03862, 2nd Dept 5-18-16

INSURANCE LAW (INSURER NOT OBLIGATED TO SATISFY JUDGMENT AGAINST ITS INSURED; INJURED PARTY FAILED TO TIMELY NOTIFY INSURER OF THE FIRE WHICH CAUSED THE DAMAGE)

/ ,

33 HOUR DELAY IN ARRAIGNMENT, UNDER THE FACTS, DID NOT RENDER STATEMENT INVOLUNTARILY MADE.

The Second Department, in affirming defendant’s conviction over a dissent, determined a 33 hour delay of arraignment did not, under the facts, render defendant’s statement involuntarily made:

… [T]he testimony at the suppression hearing demonstrated that approximately 29-33 hours passed between the defendant’s arrest and his arraignment and that he provided statements after being in custody for approximately 25-28 hours. … [T]his was not a typical armed robbery case, and … the delay in arraignment was satisfactorily explained. The NYPD coordinated with three other law enforcement agencies to investigate not only the attempted murder and two robbery charges, but also the extent to which the defendant used false identities and counterfeit money in various jurisdictions, before presenting these matters at arraignment, where a judge would be considering the likelihood that the defendant would return to court before setting bail. Notably, prior to obtaining a statement from the defendant, the lead detective traveled to the hospital where the victim was recovering, conducted a photo array identification procedure when the victim became available, and then traveled back to the station house. Under these circumstances, we conclude that the delay in arraigning the defendant was attributable to a thorough and necessary police investigation. Thus, his “detention [was not] prolonged beyond a time reasonably necessary to accomplish the tasks required to bring [him] to arraignment” … . Further, the record does not otherwise demonstrate that the police unnecessarily delayed the arraignment in order to obtain an involuntary confession … . People v Johnson, 2016 NY Slip Op 03896, 2nd Dept 5-18-16

CRIMINAL LAW (33 HOUR DELAY IN ARRAIGNMENT, UNDER THE FACTS, DID NOT RENDER STATEMENT INVOLUNTARILY MADE)/EVIDENCE (CRIMINAL LAW, 33 HOUR DELAY IN ARRAIGNMENT, UNDER THE FACTS, DID NOT RENDER STATEMENT INVOLUNTARILY MADE)

/

SIDEWALK WAS NOT USED AS A DANGEROUS INSTRUMENT IN THIS ASSAULT CASE.

The Second Department determined, under the facts, the sidewalk was not “used” as a dangerous instrument by the defendant. The defendant punched the victim who then fell and struck his head on the sidewalk, suffering very serious injury. Although it is possible to intentionally or recklessly “use” a sidewalk as a dangerous instrument, here the sidewalk was not “used” by the defendant to cause injury withn the meaning of the assault statute (Penal Law 120.05(4)):

We agree with the People's interpretation of Penal Law § 120.05(4) that the reckless mens rea must be read to modify the phrase “by means of . . . a dangerous instrument” (see Penal Law § 15.05[3]), and that the statute does not, as the Supreme Court held, require “purposeful use” of the dangerous instrument (see Penal Law § 15.15[1]…). However, we disagree with the People's contention that Penal Law § 120.05(4) does not require that the serious physical injury be recklessly caused by the use of a dangerous instrument. Such a reading of the statute ignores the definition of dangerous instrument, which expressly focuses on the circumstances in which the instrument is “used” (Penal Law § 10.00[13]), and the use-oriented approach that has evolved directly from that definition … . Moreover, a person can “use” a dangerous instrument in a reckless manner … . Therefore, a conviction under Penal Law § 120.05(4) requires legally sufficient evidence establishing that the defendant recklessly “used” the dangerous instrument. People v McElroy, 2016 NY Slip Op 03897, 2nd Dept 5-18-16

CRIMINAL LAW (SIDEWALK WAS NOT USED AS A DANGEROUS INSTRUMENT IN THIS ASSAULT CASE)/ASSAULT (SIDEWALK WAS NOT USED AS A DANGEROUS INSTRUMENT IN THIS ASSAULT CASE)/DANGEROUS INSTRUMENT (SIDEWALK WAS NOT USED AS A DANGEROUS INSTRUMENT IN THIS ASSAULT CASE)

/ ,

FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES.

The Second Department, reversing Supreme Court, determined plaintiff was not entitled to [construction] delay damages because plaintiff did not strictly comply with the delay-notice requirements spelled out in the contract as a condition precedent:

“Where a construction contract contains a condition precedent-type notice provision setting forth the consequences of a failure to strictly comply,' strict compliance will be required”… . Express conditions precedent “must be literally performed; substantial performance will not suffice,” and “[f]ailure to strictly comply with such provisions generally constitutes a waiver of a claim” … .

Here, article 11 of the primary contract between the defendant and the City, which is incorporated into the subcontract, contains such a condition-precedent type notice provision. Article 11.1.2 requires a contractor claiming to be sustaining delay damages to submit, “within forty-five (45) Days from the time such damages are first incurred, and every thirty (30) Days thereafter for as long as such damages are incurred, verified statements of the details and amounts of such damages, together with documentary evidence of such damages.” Moreover, pursuant to article 11.2, a failure “to strictly comply with the requirements of Article . . . 11.1.2 shall be deemed a conclusive waiver by the Contractor of any and all claims for damages for delay arising from such condition.”

The letters and emails relied upon by the Supreme Court and the plaintiff did not strictly comply with the contractual notice requirement, since they did not contain verified statements of the amount of delay damages allegedly sustained by the plaintiff and were unsupported by documentary evidence … . Schindler El. Corp. v Tully Constr. Co., Inc., 2016 NY Slip Op 03868, 2nd Dept 5-18-16

CONTRACT LAW (FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/LABOR-CONSTRUCTION LAW (FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/CONSTRUCTION CONTRACTS (DELAY DAMAGES, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/DELAY DAMAGES (CONSTRUCTION CONTRACTS, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/CONDITIONS PRECEDENT (CONSTRUCTION CONTRACTS, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)

/

DOCTRINE OF DEFINITENESS WAS PROPERLY NOT APPLIED, DOLLAR-AMOUNT OF THE FEE AT ISSUE COULD BE DETERMINED BY INDUSTRY PRACTICE.

The First Department, in a full-fledged opinion by Justice Manzanet-Daniels, determined the “doctrine of definiteness” should not be applied to an agreement in which the specific dollar-amount of a fee for financial advisory services, called a transaction fee, was not spelled out.  The contract stated only that the transaction fee would be “consistent with investment banking industry practice for transactions of comparable complexity, level of analysis and size.” Because the fee was ultimately determined by a method accepted in the investment banking industry, the fee was not rendered unenforceable by the “doctrine of definiteness:”

The doctrine of definiteness “assures that courts will not impose contractual obligations when the parties did not intend to conclude a binding agreement” … . It is to be sparingly used, as a “last resort,” and only when an agreement “cannot be rendered reasonably certain by reference to an extrinsic standard that makes its meaning clear” … . The Court of Appeals has cautioned that if applied with too “heavy [a] hand,” the doctrine may negate the reasonable expectations of the parties in entering into the contract … .

The “Transaction Fee” provision explicitly references the type of “commercial practice, or trade usage” New York courts routinely rely upon to render a price term sufficiently definite … . The fee [is] enforceable inasmuch as it may be ascertained from public price indices and industry practice … .

Where, as here, the record demonstrates that sophisticated parties intended to be bound by an agreement, the doctrine of definiteness should not be used to defeat the bargain of the parties … . Cowen & Co., LLC v Fiserv, Inc., 2016 NY Slip Op 03840, 1st Dept 5-17-16

CONTRACT LAW (DOCTRINE OF DEFINITENESS WAS PROPERLY NOT APPLIED, DOLLAR-AMOUNT OF THE FEE AT ISSUE COULD BE DETERMINED BY INDUSTRY PRACTICE)/DOCTRINE OF DEFINITENESS (CONTRACT LAW, DOCTRINE OF DEFINITENESS WAS PROPERLY NOT APPLIED, DOLLAR-AMOUNT OF THE FEE AT ISSUE COULD BE DETERMINED BY INDUSTRY PRACTICE)

/ ,

QUESTION OF FACT WHETHER PLAINTIFF EMPLOYEE WAS TERMINATED (NOT A VIOLATION OF THE AT WILL CONTRACT) OR WHETHER DEFENDANT EMPLOYER VIOLATED THE NO ORAL MODIFICATION CLAUSE.

The First Department, over an extensive two-justice dissent, reversing (modifying) Supreme Court, determined plaintiff employee should not have been granted summary judgment against defendant employer in this action alleging breach of an employment contract.  Although the contract was deemed to have created an at will employment arrangement, Supreme Court held that the “no oral modification” clause was violated when defendant employer modified plaintiff's duties without a written agreement signed by the plaintiff. The First Department found that there was a question of fact whether plaintiff was terminated (not prohibited by the contract), or whether the contract was modified without a written agreement (prohibited by the contract):

“[A]bsent an agreement establishing a fixed duration, an employment relationship is presumed to be a hiring at will, terminable at any time by either party” ,,, . The presumption can be rebutted by evidence of a limitation on the employer's right to discharge the employee at will … .

The inclusion of the no oral modification clause in the employment agreement does not, in and of itself, suffice to rebut the at-will presumption. While the clause precluded the modification of “any provision” of the agreement without a writing signed by the party against whom enforcement was sought, there is no express provision in the agreement that precluded defendant from terminating plaintiff without cause. However, as Supreme Court found, the no oral modification clause is an enforceable contract term even if the employment was at will  … . * * *

Nevertheless, while the court correctly found that the no oral modification clause was enforceable and barred defendant from unilaterally altering the terms of plaintiff's employment agreement without a writing, issues of fact exist that preclude the granting of summary judgment in plaintiff's favor. These include whether or not defendant terminated plaintiff's employment or merely modified it when it removed plaintiff as president … .  Gootee v Global Credit Servs., LLC, 2016 NY Slip Op 03984, 1st Dept 5-19-16

CONTRACT LAW (QUESTION OF FACT WHETHER PLAINTIFF EMPLOYEE WAS TERMINATED [NOT A VIOLATION OF THE AT WILL CONTRACT] OR WHETHER DEFENDANT EMPLOYER VIOLATED THE NO ORAL MODIFICATION CLAUSE)/EMPLOYMENT LAW (QUESTION OF FACT WHETHER PLAINTIFF EMPLOYEE WAS TERMINATED [NOT A VIOLATION OF THE AT WILL CONTRACT] OR WHETHER DEFENDANT EMPLOYER VIOLATED THE NO ORAL MODIFICATION CLAUSE)/AT WILL EMPLOYMENT (QUESTION OF FACT WHETHER PLAINTIFF EMPLOYEE WAS TERMINATED [NOT A VIOLATION OF THE AT WILL CONTRACT] OR WHETHER DEFENDANT EMPLOYER VIOLATED THE NO ORAL MODIFICATION CLAUSE)

/

STATUTE REQUIRING TIMELY NOTICE OF THE ACCIDENT DID NOT REQUIRE NOTICE OF ALL THE INJURIES STEMMING FROM THE ACCIDENT.

The Third Department determined the statute requiring notice of an accident did not require notice of all the injuries. Here the self-insured employer was timely notified of the accident and claimant's knee injury but was not notified of other injuries stemming from the accident until a year later:

Workers' Compensation Law § 18 provides, in relevant part, that written “[n]otice of an injury . . . for which compensation is payable . . . shall be given to the employer within thirty days after the accident causing the injury.” The same provision also provides that the Board may excuse late notice upon certain grounds, including “that the employer, or his or its agents . . . had knowledge of the accident.” Here, the self-insured employer was provided with notice of the accident and claimant's resulting left knee injury within the statutory 30-day period, but was unaware of claimant's other injuries until nearly a year later when she filed her C-3 claim. The self-insured employer contends that this Court should construe the statutory phrase “had knowledge of the accident” to mean “had knowledge of the injury,” and, as a result, conclude that claimant's late notice for the additional injuries is inexcusable pursuant to Workers' Compensation Law § 18. We reject the self-insured employer's interpretation of Workers' Compensation Law § 18, as it contravenes two foundational rules of statutory construction. Matter of Logan v New York City Health & Hosp. Corp., 2016 NY Slip Op 03776, 3rd Dept 5-12-16

WORKERS' COMPENSATION LAW (STATUTE REQUIRING TIMELY NOTICE OF THE ACCIDENT DID NOT REQUIRE NOTICE OF ALL THE INJURIES STEMMING FROM THE ACCIDENT)

/

POSSESSION OF MARIJUANA CONSTITUTED DISQUALIFYING MISCONDUCT.

The Third Department determined claimant's criminal conviction disqualified him from receiving unemployment insurance benefits. Claimant had been a service aide for the developmentally disabled for 25 years and pled guilty to possession of marijuana:

Criminal convictions arising from conduct occurring outside the workplace have been found to constitute disqualifying misconduct where they demonstrate a breach of the standards of behavior to be reasonably expected by an employer in light of the nature of the employment involved … . Significantly, claimant's job responsibilities included, among other things, dispensing medications to developmentally disabled individuals. Given the environment in which claimant worked, it was reasonable for the employer to expect that claimant would not illegally use or possess controlled substances. Clearly, claimant's criminal conduct posed a risk to the employer's mission and was detrimental to its interests. Therefore, we find that substantial evidence supports the Board's finding that claimant engaged in disqualifying misconduct … . Matter of Hall (Commissioner of Labor), 2016 NY Slip Op 03797, 3rd Dept 5-12-16

UNEMPLOYMENT INSURANCE (POSSESSION OF MARIJUANA CONSTITUTED DISQUALIFYING MISCONDUCT)

/

 DISPUTED BOUNDARY PROVEN THROUGH DOCTRINE OF PRACTICAL LOCATION.

The Third Department determined the disputed boundary line was established by the doctrine of practical location:

Under … doctrine [of practical location], “the practical location of a boundary line and an acquiescence of the parties therein for a period of more than the statutory period governing adverse possession is conclusive of the location of the boundary line” … . Moreover, “application of the doctrine requires a clear demarcation of a boundary line and proof that there is mutual acquiescence to the boundary by the parties such that it is definitely and equally known, understood and settled” … .

Here, defendant submitted plaintiff's deposition testimony in support of his motion. Plaintiff had lived continuously upon his property for approximately 23 years, and he acknowledged that, during that time, the occupiers of defendant's parcel had used the strip to access a garage in the rear of their property, and neither plaintiff nor his parents had ever attempted to prevent them from doing so. Plaintiff further acknowledged that there was previously a line of grass running between the two parcels that created the appearance of two separate driveways, and that the remnants of that line were still visible as a triangular patch or “point” of grass. Defendant also submitted an affidavit from a neighbor who had lived across the street for approximately 50 years. This neighbor confirmed that there had been a line of grass that ran between the parties' parcels, and that it had appeared that the occupants had always agreed that their respective driveways were on either side of that line. Finally, plaintiff submitted the affidavit of defendant's immediate predecessor in interest, who had lived on the property for approximately 40 years and had later rented it to tenants. This witness stated that, throughout his involvement with the property, the occupants of the two parcels had always mutually agreed that the boundary line was located along the line of grass bisecting the parcels' driveways. His affidavit included an aerial photograph portraying the boundary as a line extending along the remaining triangular strip of grass. Lounsbury v Yeomans, 2016 NY Slip Op 03798, 3rd Dept 5-12-16

REAL PROPERTY (DISPUTED BOUNDARY PROVEN THROUGH DOCTRINE OF PRACTICAL LOCATION)/PRACTICAL LOCATION, DOCTRIN OF, (DISPUTED BOUNDARY PROVEN THROUGH DOCTRINE OF PRACTICAL LOCATION)

/

PISTOL PERMIT PROPERLY REVOKED BY FAMILY COURT.

The Third Department determined Family Court properly revoked petitioner's pistol permit:

Here, the evidence included the report of a police investigator who interviewed both petitioner and his former spouse regarding the 2008 domestic dispute. The former spouse recounted that, during a heated dispute over the status of their marriage, petitioner punched several holes in the wall, removed his pistol from a drawer in his bedroom, began to load it and told her that “he was going to give her something to call the police about.” Contrary to petitioner's claim, respondent was entitled to rely on the hearsay statements contained in the report … . Although petitioner denied threatening his former spouse and testified that he was merely packing the gun with the rest of his belongings in an effort to leave the marital home, respondent expressly found the former spouse's account to be more credible, and we defer to such credibility determinations … . Accordingly, we find no abuse of discretion in respondent's determination that petitioner handled his pistol in an irresponsible manner and that revocation of his permit was therefore justified … . Matter of Schmitt v Connolly, 2016 NY Slip Op 03775, 3rd Dept 5-12-6

PISTOL PERMITS (PISTOL PERMIT PROPERLY REVOKED BY FAMILY COURT)

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy