You are here: / / DEFENDANT HAD WITHHELD PAYMENT ON THE CONTRACT AS AN OFFSET FOR THE LIQUIDATED...
,

DEFENDANT HAD WITHHELD PAYMENT ON THE CONTRACT AS AN OFFSET FOR THE LIQUIDATED DAMAGES PROVISION OF THE CONTRACT; THE AWARD OF LIQUIDATED DAMAGES TO THE DEFENDANT THEREFORE CONSTITUTED A DOUBLE RECOVERY (FIRST DEPT). ​

The First Department, reversing Supreme Court, determined defendant should not have been awarded summary judgment on the liquidated damages counterclaim because defendant had withheld payment on the contract as an offset to the liquidated damages:

Supreme Court should have denied summary judgment in defendant’s favor on the liquidated damages counterclaim. To be sure, the liquidated damages provision of the contract, providing for damages of $100 for each day that plaintiff failed to timely respond to a request for repairs or to complete repairs already begun and $100 for failing to timely provide a written estimate, was not an unenforceable penalty … . However, to the extent defendant has withheld payment from plaintiff for work performed to offset liquidated damages, the award of liquidated damages constitutes a double recovery. Summit Rest. Repairs & Sales, Inc. v New York City Dept. of Educ., 2022 NY Slip Op 00526, First Dept 1-27-22

 

You might also like
THE ALLEGATIONS OF DEFENDANTS’ CONDUCT DURING PHOTO SHOOTS OF PLAINTIFF-MODEL WHEN SHE WAS 16 AND 17 YEARS OLD MET THE “SEXUAL CONDUCT” CRITERIA FOR THE EXTENDED STATUTE OF LIMITATIONS UNDER THE CHILD VICTIMS ACT (CVA), THE COMPLAINT STATED CAUSES OF ACTION FOR INVASION OF PRIVACY PURSUANT TO CIVIL RIGHTS LAW SECTION 50 (FIRST DEPT).
PLAINTIFF SUED THE DEVELOPER OF PROPERTY ADJACENT TO PLAINTIFF’S BUILDING ALLEGING EXCAVATION WORK CAUSED PLAINTIFF’S BUILDING TO SETTLE AND LEAN; THE CITY ISSUED A STOP-WORK ORDER STEMMING FROM PLAINTIFF’S COMPLAINT; DEFENDANT-DEVELOPER THEN COUNTERCLAIMED ALLEGING PLAINTIFF WAS NEGLIGENT IN NOT MAINTAINING PLAINTIFF’S BUILDING SUCH THAT THE EXCAVATION WORK WOULD NOT DAMAGE IT, RESULTING IN THE STOP-WORK ORDER AND CAUSING THE DEVELOPER PURELY ECONOMIC LOSS OF AT LEAST $16 MILLION; SUPREME COURT LET THE COUNTERCLAIM STAND BUT THE FIRST DEPARTMENT DISMISSED IT; PLAINTIFF DID NOT OWE A DUTY TO THE DEVELOPER AND THE DEVELOPER WAS NOT ENTITLED TO PURELY ECONOMIC DAMAGES (FIRST DEPT).
VERTICALLY-STACKED SHEETS OF METAL ON A DOLLY FELL ON PLAINTIFF WHEN HE MOVED IT; THE HEIGHT DIFFERENTIAL WAS NOT DE MINIMUS AND PLAINTIFF WAS ENTITLED TO SUMMARY JUDGMENT IN THIS LABOR LAW 240(1) FALLING-OBJECT CASE; THE FACT THAT THE DOLLY BELONGED TO ANOTHER CONTRACTOR WAS NOT DISPOSTIVE, PLAINTIFF WAS DIRECTED TO MOVE THE DOLLY AS PART OF HIS EMPLOYMENT (FIRST DEPT).
A JUDGE CANNOT ENTER A JUDGMENT WHICH DOES NOT CONFORM TO THE ORDER; HERE THE JUDGMENT ELIMINATED MILLIONS OF DOLLARS IN DAMAGES AND EXTINGUISHED A DEFENDANT’S LIABILITY (FIRST DEPT).
THE COMMERCIAL LEASE GUARANTEE MET THE DEFINITION OF AN INSTRUMENT FOR THE PAYMENT OF MONEY; THE COVID-19 RESTRICTIONS ON ENFORCEMENT OF COMMERCIAL LEASE GUARANTEES DO NOT APPLY; THE WARRANTY OF HABITABILITY DEFENSE IS NOT AVAILABLE (FIRST DEPT).
AN ACCOUNT-STATED ACTION IS NOT DUPLICATIVE OF A BREACH-OF-CONTRACT ACTION; HERE PLAINTIFF DIVORCE ATTORNEYS PROPERLY SOUGHT PAYMENT UNDER BOTH ACCOUNT-STATED AND BREACH-OF-RETAINER-AGREEMENT THEORIES AND THE COURT PROPERLY AWARDED SUMMARY JUDGMENT ON THE ACCOUNT-STATED CAUSE OF ACTION (FIRST DEPT).
THE TENANT MADE GOOD FAITH EFFORTS TO CURE THE DEFAULTS CITED BY THE LANDLORD AND WAS ENTITLED TO A YELLOWSTONE INJUNCTION TOLLING TENANT’S TIME TO CURE (FIRST DEPT). ​
HERE THE “RENEWED” SUMMARY JUDGMENT MOTION WAS BASED ON EVIDENCE WHICH WAS AVAILABLE FOR THE FIRST MOTION; THE “RENEWED” MOTION SHOULD HAVE BEEN DENIED (FIRST DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2026 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

IN THIS SCAFFOLD-FALL CASE, EVIDENCE PLAINTIFF WAS INSTRUCTED TO USE GUARD RAILS... A PRE-JOINDER MOTION FOR SUMMARY JUDGMENT MUST BE DENIED (FIRST DEPT).