You are here: / / THE HANDWRITTEN ADDITION TO THE PRINTED CONTRACT IS PRESUMED TO EXPRESS...
,

THE HANDWRITTEN ADDITION TO THE PRINTED CONTRACT IS PRESUMED TO EXPRESS THE LATEST INTENTION OF THE PARTIES; HERE THE ENTRY CREATED AMBIGUITY IN THE “NO DAMAGES FOR DELAY” CLAUSE REQUIRING DISCOVERY (FIRST DEPT). ​

The First Department, reversing Supreme Court, determined a handwritten entry in a printed contract is presumed to express the latest intention of the parties and created ambiguity requiring discovery:

The subcontractor agreement between plaintiff and defendant JDS Construction Group LLC contains clauses precluding damages for delay. It also provides that if plaintiff’s work was “delayed or disrupted by fault of [JDS], Architect, or any other contractor, or by abnormal weather conditions, then the time fixed for the completion of the Work shall be extended for a period equivalent to the time actually lost, in the discretion of [JDS] and compensated for additional, mutually agreed to costs,” with the words in italics handwritten onto the typed agreement.

… [A] handwritten provision that conflicts with the language of the preprinted form document will control, “as it is presumed to express the latest intention of the parties” … . The handwritten amendment to the no-damages-for-delay clause renders the clause ambiguous as to whether plaintiff is entitled to be compensated for costs incurred as a result of such delays, which requires discovery to discern the parties’ intent … . Henick-Lane, Inc. v 616 First Ave. LLC, 2023 NY Slip Op 01163, First Dept 3-7-23

Practice Point: A handwritten entry in a printed contract is presumed to reflect the latest intention of the parties.

 

You might also like
Judges Not Entitled to Retroactive Monetary Damages Re: Legislature’s Failure to Enact Cost of Living Increases Since 2000
PLAINTIFF’S MOTION TO AMEND HER COMPLAINT TO ADD NAMES OF POLICE OFFICERS SUED AS JOHN DOES SHOULD NOT HAVE BEEN GRANTED, THE OFFICERS ARE NOT UNITED IN INTEREST WITH THE CITY DEFENDANT, FAILURE TO NAME THE OFFICERS WAS NOT A MISTAKE, AND PLAINTIFF FAILED TO MAKE A DILIGENT EFFORT TO LEARN THE OFFICERS’ NAMES BEFORE THE STATUTE OF LIMITATIONS EXPIRED (FIRST DEPT).
IN THIS ARTICLE 78 PROCEEDING, NO APPEAL LIES FROM A JUDGE’S DECLINING TO SIGN AN ORDER TO SHOW CAUSE; THE ONLY REMEDY IS A MOTION TO VACATE THE FINAL JUDGMENT (FIRST DEPT).
THE JURY’S FINDING THAT PLAINTIFF IN THIS SLIP AND FALL CASE WAS NEGLIGENT BUT THAT DEFENDANT WAS 100% RESPONSIBLE WAS AGAINST THE WEIGHT OF THE EVIDENCE; ALLOWING PLAINTIFF’S DOCTOR TO TESTIFY DEFENDANT’S DOCTOR WAS HIRED BY AN INSURANCE COMPANY, WITHOUT GIVING A CURATIVE INSTRUCTION, WAS REVERSIBLE ERROR (FIRST DEPT).
CEREMONIAL MARRIAGE SUFFICIENTLY PROVEN, CHILD ENTITLED TO SUPPORT.
HUSBAND DID NOT DEMONSTRATE ENTITLEMENT TO 50% OF THE APPRECIATION OF WIFE’S SEPARATE PROPERTY IN THIS DIVORCE ACTION (FIRST DEPT).
THE ONLY EVIDENCE OF DEFENDANT’S PARTICIPATION IN THE SHOOTING WAS DNA ON A HANDGUN; THE EVIDENCE OF MURDER AND POSSESSION OF A WEAPON WAS LEGALLY INSUFFICIENT; THE VERDICT WAS AGAINST THE WEIGHT OF THE EVIDENCE; INDICTMENT DISMISSED (FIRST DEPT).
LIABILITY UNDER LABOR LAW 200 DOES NOT REQUIRE THAT PLAINTIFF BE ENGAGED IN CONSTRUCTION WORK; HERE PLAINTIFF FELL OFF THE TOP OF A TRACTOR-TRAILER; THE LABOR LAW 200 CAUSE OF ACTION SHOULD NOT HAVE BEEN DISMISSED (FIRST DEPT).

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2025 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

PERMIT/ORDER ALLOWING DEVELOPMENT OF MARINAS ON LOWER SARANAC LAKE IN THE ADIRONDACK... THE PROCEEDS OF THE SALE OF COLLATERAL TO THE MAJORITY LENDERS WERE NOT DISTRIBUTED...