You are here: / / FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN...
,

FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES.

The Second Department, reversing Supreme Court, determined plaintiff was not entitled to [construction] delay damages because plaintiff did not strictly comply with the delay-notice requirements spelled out in the contract as a condition precedent:

“Where a construction contract contains a condition precedent-type notice provision setting forth the consequences of a failure to strictly comply,' strict compliance will be required”… . Express conditions precedent “must be literally performed; substantial performance will not suffice,” and “[f]ailure to strictly comply with such provisions generally constitutes a waiver of a claim” … .

Here, article 11 of the primary contract between the defendant and the City, which is incorporated into the subcontract, contains such a condition-precedent type notice provision. Article 11.1.2 requires a contractor claiming to be sustaining delay damages to submit, “within forty-five (45) Days from the time such damages are first incurred, and every thirty (30) Days thereafter for as long as such damages are incurred, verified statements of the details and amounts of such damages, together with documentary evidence of such damages.” Moreover, pursuant to article 11.2, a failure “to strictly comply with the requirements of Article . . . 11.1.2 shall be deemed a conclusive waiver by the Contractor of any and all claims for damages for delay arising from such condition.”

The letters and emails relied upon by the Supreme Court and the plaintiff did not strictly comply with the contractual notice requirement, since they did not contain verified statements of the amount of delay damages allegedly sustained by the plaintiff and were unsupported by documentary evidence … . Schindler El. Corp. v Tully Constr. Co., Inc., 2016 NY Slip Op 03868, 2nd Dept 5-18-16

CONTRACT LAW (FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/LABOR-CONSTRUCTION LAW (FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/CONSTRUCTION CONTRACTS (DELAY DAMAGES, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/DELAY DAMAGES (CONSTRUCTION CONTRACTS, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)/CONDITIONS PRECEDENT (CONSTRUCTION CONTRACTS, FAILURE TO STRICTLY COMPLY WITH CONDITION-PRECEDENT NOTICE PROVISIONS IN THE CONSTRUCTION CONTRACT PRECLUDED RECOVERY FOR DELAY DAMAGES)

You might also like
Priority in Custody Disputes Given to Party Initially Awarded Custody
Parol Collateral Agreement Can Be Alleged Where Written Contract Does Not Embody Entire Agreement/Where Existence of Contract Is Disputed, Causes of Action for Unjust Enrichment and Quantum Meruit Are Okay/Courts Can Not Excuse Failure to Strictly Comply with Lien Law Requirements
NO PROOF DEFENDANT WAS DEPRIVED OF HIS LIMITED RIGHT TO SPEAK TO COUNSEL BEFORE TAKING BLOOD-ALCOHOL TEST, SUPPRESSION SHOULD NOT HAVE BEEN GRANTED, APPLICABLE LAW EXPLAINED.
PLAINTIFF WAS NOT ENTITLED TO THE PRESUMPTION DEFENDANT RECEIVED A LETTER ALLEGEDLY REQUESTING THAT SURVEILLANCE VIDEO BEFORE AND AFTER PLAINTIFF’S SLIP AND FALL BE PRESERVED AS THERE WAS NO PROOF OF MAILING, DEFENDANT SHOULD NOT HAVE BEEN SANCTIONED FOR SPOLIATION PURSUANT TO CPLR 3126 (SECOND DEPT).
THE MATERNAL GRANDMOTHER HAD STANDING TO PETITION FOR VISITATION AFTER MOTHER’S DEATH; FAMILY COURT SHOULD NOT HAVE DENIED THE PETITION WITHOUT HOLDING A “BEST INTERESTS” HEARING (SECOND DEPT). ​
PLAINTIFFS DID NOT ALLEGE THAT DEFENDANT CREATED THE DANGEROUS CONDITION AND DEFENDANT DEMONSTRATED IT DID NOT HAVE NOTICE OF THE CONDITION, THEREFORE DEFENDANT’S MOTION FOR SUMMARY JUDGMENT IN THIS ICE AND SNOW SLIP AND FALL CASE SHOULD HAVE BEEN GRANTED (FIRST DEPT).
SUCCESSIVE SUMMARY JUDGMENT MOTIONS WHICH ARE NOT BASED ON INFORMATION WHICH WAS NOT AVAILABLE AT THE TIME OF THE PRIOR MOTIONS SHOULD NOT BE ENTERTAINED BY THE COURT (SECOND DEPT).
FATHER’S MOTION TO VACATE THE DEFAULT DISMISSAL OF HIS VISITATION PETITION SHOULD HAVE BEEN GRANTED, LIBERAL POLICY IN FAVOR OF VACATING DEFAULT NOTED.

Categories

Sign Up for the Mailing List to Be Notified When the Site Is Updated.

  • This field is for validation purposes and should be left unchanged.

Copyright © 2025 New York Appellate Digest, Inc.
Site by CurlyHost | Privacy Policy

DOCTRINE OF DEFINITENESS WAS PROPERLY NOT APPLIED, DOLLAR-AMOUNT OF THE FEE... SIDEWALK WAS NOT USED AS A DANGEROUS INSTRUMENT IN THIS ASSAULT CASE.